admission, enrollment, quota, eligibility membership, or other requirements of condition which individuals must meet in order to be provided any service or benefit; the assignment of times or places for the provision of services on the basis of discriminatory distinctions which may be made of the patients to be served. (b) The Government reserves the right to reassume this contract in whole or in part whenever the Contractor fails to comply with the requirements of this clause. (End of clause) CLAUSE NO. 38-PRICE REDUCTION FOR The following clause applies to all contracts where cost and pricing data is required in accordance with P.L. 87-653. Price Reduction for Defective Cost or (a) If the Contracting Officer determines that any price negotiated in connection with this contract or any cost reimbursable under this contract was increased by any significant sums because the Contractor, or any subcontractor pursuant to the Clause of this contract entitled "Subcontractor Cost or Pricing Data" or "Subcontractor Cost or Pricing Data-Price Adjustments," or any subcontract clause therein required, furnished incomplete or inaccurate cost or pricing data or data not current as certified in its Contractor's Certificate of Current Cost or Pricing Data, then such price or cost shall be reduced accordingly and the contract shall be modified in writing to reflect such reduction. (b) Failure to agree on a reduction shall be a dispute concerning a question of fact within the meaning of the “Disputes” clause of this contract. (NOTE: Since this contract is subject to reduction under this clause by reason of defective cost or pricing data submitted in connection with certain subcontracts, it is expected that the Contractor may wish to inIclude a clause in each such subcontract requiring the subcontractor to appropriately indemnify the Contractor. It is also expected that any subcontractor subject to such indemnification will generally require substantially similar indemnification for defective cost or pricing data required to be submitted by its lower tier subcontractors.) (End of clause) CLAUSE NO. 39-SUBCONTRACTOR COST AND PRICING DATA The following clauses should be included in all contracts, when the subcontracts of the type and size described therein are contemplated. Subcontractor Cost and Pricing Data (June 1977) (a) The Contractor shall require subcontractors hereunder to submit in writing cost or pricing data under the following circumstances: (1) Prior to award of any cost-reimbursed type, time and material, labor-hour, incentive, or price redeterminable subcontract the price of which is expected to exceed $100,000; and (2) Prior to the award of any other subcontract, the price of which is expected to exceed $100,000, or to the pricing of any subcontract change or other modification of which the price adjustment is expected to exceed $100,000, where the price or price adjustment is not based on adequate price competition, established catalog or market price or commercial items sold in substantial quantities to the general public, or prices set by law or regulation. (b) The Contractor shall require subcontractors to certify, substantially the same form as that used in the certificate by the Prime Contractor to the Government, that, to the best of their knowledge and belief, the cost and pricing data submitted under (a) above are accurate, complete, and current as of the date of the execution, which date shall be as close as possible to the date of agreement on the negotiated price of the subcontract or subcontract change or modification. (c) The Contractor shall insert the substance of this clause including this paragraph (c) in each of its cost-reimbursement type, time and material, labor-hour, price redeterminable, or incentive subcontracts hereunder, and in any other subcontract hereunder which exceeds $100,000 unless the price thereof is based on adequate price competition, established catalog or market prices of commercial items sold in substantial quantities to the general public, or prices set by law or regulation. In each such expected subcontract hereunder which exceeds $100,000, the Contractor shall insert the substance of the following clauses: Subcontractor Cost and Pricing Data-Price Adjustments (a) Paragraphs (b) and (c) of this clause shall become operative only with respect to any change or other modification made pursuant to one or more provisions of this contract which involves a price adjustment in excess of $100,000. The requirements of this clause shall be limited to such price adjust ments. (b) The Contractor shall require subcontractors hereunder to submit cost or pricing data under the following circumstances: (1) Prior to award of any cost-reimbursement type, time and material, labor-hour, incentive, or price redeterminable subcontract, the price of which is expected to exceed $100,000; and (2) Prior to award of any other subcontract, the price of which is expected to exceed $100,000, or to the pricing of any subcontract change or other modification for which the price adjustment is expected to exceed $100,000, where the price or price adjustment is not based on adequate price competition, established catalog or market prices of commercial items sold in substantial quantities to the general public, or prices set by law or regulation. (c) The Contractor shall require subcontractors to certify, in substantially the same form as that used in the Certificate by the Prime Contractor to the Government, that, to the best of their knowledge and belief, the cost and pricing data submitted under (b) above are accurate, complete, and current as of the date of the execution, which date shall be as close as possible to the date of agreement on the negotiated price of the contract modification. (d) The Contractor shall insert the substance of this clause including this paragraph (d) in each subcontract hereunder which exceeds $100,000. (End of clause) CLAUSE NO. 40-PENALTIES (JUNE 1977) (a) Any officer, director, agent, employee or such other person connected in any capacity with this contract or any subcontract thereunder that embezzles, willfully misapplies, steals or obtains by fraud any of the money, funds, assets or property provided through the contract shall be fined not more than $10,000 or imprisoned for more than two years, or both; Provided, That if the amount embezzled, misapplied, stolen, or obtained by fraud does not exceed $100, such person shall be fined not more than $1,000 or imprisoned not more than one year, or both. (b) The Contractor agrees to insert the clause in all subcontracts. (End of clause) CLAUSE NO. 41-EFFECT ON EXISTING RIGHTS (JUNE 1977) (a) Nothing in this contract shall be construed as: (1) Affecting, modifying, diminishing, or otherwise impairing the sovereign immunity for suit enjoyed by an Indian tribe; or, (2) Authorizing or requiring the termination of any existing trust responsibility of the United States with respect to the Indian people. (End of clause) CLAUSE NO. 42-GENERAL SERVICES ADMINISTRATION (GSA) Supply SOURCES Indian tribal organizations which are awarded cost-reimbursement type contracts under the Indian Self-Determination Act, may be authorized to utilize GSA supply sources. The following clause will be inserted in all cost-reimbursement type contracts under which the Contractor may be authorized to acquire items for the account of the Government from GSA supply sources: General Services Administration Supply Sources (June 1977) The Contracting Officer may issue the Contractor an authorization to utilize General Services Administration supply sources for property to be used in the performance of this contract. Title to all property acquired by the Contractor under such an authorization shall vest in the Government, (1) unless otherwise specifically provided in the contract, (2) unless otherwise provided in the Government Property clause of this contract, or (3) in the absence of both the conditions in (1) and (2) of the clause. However, such property shall not be considered to be "Government-furnished property." (End of clause) (b) Insert the following clauses in fixed price contracts awarded under the Indian Self-Determination Act as described in Subpart PHS 380.4: CLAUSE NO. 1–DEFINITIONS (JUNE 1977) As used throughout this contract, the following terms shall have the meanings set forth below: (a) The term "Secretary” means the Secretary, the Under Secretary, or any Assistant Secretary of the Department of Health and Human Services and the term "his/her duly authorized representative" means any person or persons or board (other than the Contracting Officer) authorized to act for the Secretary. (b) The term "Contracting Officer" means the person executing this contract on behalf of the Government, and any other officer or employee who is properly designated Contracting Officer; and the term includes, except as otherwise provided in this contract, the authorized representative of the Contracting Officer acting within the limits of his/her authority. (c) The term "Department" means the Department of Health and Human Services (HHS). (d) The term "constituent agency" means the agency of the Department responsible for the administration of this contract. (e) Except as otherwise provided in this contract, the term "subcontract" includes purchase orders under this contract. (f) The term "Project Officer" means the person representing the Government for the purpose of technical direction of contract performance. The Project Officer is not authorized to issue any instructions or directions which effect any increase or decrease in the cost of this contract or which change the period of this contract. (End of clause) CLAUSE NO. 2-DISPUTES (JUNE 1977) (a) Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his/her decision to writing and mail or otherwise furnish a copy thereof to the Contractor. The decision of the Contracting Officer shall be final and conclusive unless, within 30 days from the date of receipt of such copy, the Contractor mails or otherwise furnishes to the Contracting Officer a written appeal addressed to the Secretary. The decision of the Secretary or his/her duly authorized representative for the determination of such appeals shall be final and conclusive unless determined by a court of competent jurisdiction to have been fraudulent, or capricious, or arbitrary, or so grossly erroneous as necessarily to imply bad faith, or not supported by substantial evidence. In connection with any appeal proceeding under this clause, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its appeal. Pending final decision of a dispute hereunder, the Contractor shall proceed diligently with the performance of the contract and in accordance with the Contracting Officer's decision. (b) This "Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph (a) above; Provided, That nothing in this contract shall be construed as making final the decision of any administrative official, representative, or board on a question of law. (End of clause) CLAUSE NO. 3-CONTRACT WORK HOURS AND SAFETY STANDARD ACT-OVERTIME COMPENSATION (JUNE 1977) This contract, to the extent it is of a character specified in the Contract Work Hours and Safety Standards Act (40 U.S.C. 327330), is subject to the following provisions and exceptions of such Act and the regulations of the Secretary of Labor thereunder. (a) Overtime requirements. No Contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any laborer or mechanic in any workweek in which he/ she is employed on such work to work in excess of eight hours in any calendar day or in excess of forty hours in such workweek on work subject to the provisions of the Contract Work Hours Standard Act unless such laborer or mechanic receives compensation at a rate not less than one and onehalf times his/her basic rate of pay for all such hours worked in excess of eight hours in any calendar day or in excess of forty hours in such workweek, whichever is the greater numbers of overtime hours. (b) Violation; liability for unpaid wages; liquidated damages. In the event of any violation of the provisions of paragraph (a), the Contractor and any subcontractor responsible therefor shall be liable to any affected employee for his/her unpaid wages. In addition, such Contractor and subcontractor shall be liable to the United States for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic employed in violation of the provisions of paragraph (a) at the sum of $10 for each calendar day on which such employee was required or permitted to be employed on such work in excess of eight hours or in excess of the standard workweek of forty hours without payment of the overtime wages required by paragraph (a). (c) Withholding for unpaid wages and liquidated damages. The Contracting Officer may withhold from the Government Prime Contractor, from any moneys payable on account of work performed by the Contractor or subcontractor, such sums as may administratively be determined to be necessary to satisfy any liabilities of such Contractor or subcontractor for unpaid wages and liquidated damages as provided in the provisions of paragraph (b). (d) Subcontracts. The Contractor shall insert paragraphs (a) through (d) of this clause in all subcontracts, and shall require their inclusion in all subcontracts of any tier. (e) Records. The Contractor shall maintain payroll records containing the information specified in 29 CFR 516.2(a). Such records shall be preserved for three years from the completion of the contract. This requirement does not apply where the tribal contractor is the governing body of the Tribe and the work is being performed by the tribal organization or Tribe with its own regular employees. (End of Clause) CLAUSE NO. 4-WALSH-HEALEY PUBLIC If this contract is for the manufacture or furnishing of materials, supplies, articles, or equipment in an amount which exceeds or may exceed $10,000 and is otherwise subject to the Walsh-Healey Public Contracts Act, as amended (41 U.S. Code 34-45), there are hereby incorporated by reference all representations and stipulations required by the Secretary of Labor, such representations and stipulations being subject to all applicable rulings and interpretations of the Secretary of Labor which are now or may hereafter be in effect. This requirement does not apply where the tribal contractor is the governing body of the Tribe and the work is being performed by the tribal organization or Tribe with its own regular employees. (End of Clause) CLAUSE No. 5-CONVICT LABOR (JUNE 1977) In connection with the performance of work under this contract, the Contractor agrees not to employ any person undergoing sentence of imprisonment at hard labor except as provided by Public Law 89-176, September 10, 1965 (18 U.S.C. 4082(c)(2) and Executive Order No. 11755, December 29, 1973. (End of clause) CLAUSE No. 6—NOTICE TO THE GOVERNMENT OF DELAYS (JUNE 1977) Whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this contract, the Contractor shall within ten days give notice thereof, including all relevant information with respect thereto, to the Contracting Officer. (End of clause) CLAUSE NO. 7—Assignment of Claims (JUNE 1977) (a) Pursuant to the provisions of the Assignment of Claims Act of 1940, as amended (31 U.S.C. 203, 41 U.S.C. 15), if this contract provides for payment aggregating $1,000 or more, claims for moneys due or to become due the Contractor from the Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or more parties participating in such financing. Unless otherwise provided in this contract payments to assignee of any moneys due or due to become due under this contract shall not, to the extent provided in said Act, as amended, be subject to reduction or setoff. (The preceding sentence applies only if this contract is made in time of war or national emergency as defined in said Act and is with the Department of Defense, the General Services Administration, the Atomic Energy Commission, the National Aeronautics and Space Administration, the Federal Aviation Agency, or any other department or agency of the United States designated by the President pursuant to Clause 4 of the proviso of section 1 of the Assignment of Claims Act of 1940, as amended by the Act of May 15, 1951, 65 Stat. 41). (b) In no event shall copies of this contract or of any plans, specifications, or other similar documents relating to work under this contract, if marked "Top Secret," "Secret," or “Confidential,” be furnished to any assignee of any claim arising under this contract or to any other person not entitled to receive the same. However, a copy of any part or all of this contract so marked may be furnished, or any information contained therein may be disclosed, to such assignee upon the prior written authorization of the Contracting Officer. (End of clause) CLAUSE NO. 8-OFFICIALS NOT TO BENEFIT (JUNE 1977) No member of or delegate to Congress, or resident commissioner, shall be admitted to any share or part of this contract, or to any benefit that may arise therefrom; but this provision shall not be construed to extend to this contract if made with a corporation for its general benefit. (End of clause) CLAUSE NO. 9—ANTI-KICKBACK ACT (JUNE 1977) (a) Public Law 86-695, September 2, 1960 (41 U.S.C. 51-54) among other things, prohibits the payment, directly or indirectly, by or on behalf of a subcontractor in any tier under any Government negotiated contract of any fee, gift, or gratuity to the prime contractor or any officer, agent, partner or employee thereof, as an inducement or acknowledgement for the award of a subcontract or order. (b) The provisions of Public Law 86-695 are applicable this contract and any subcontracts entered into under the contract. (End of clause) CLAUSE NO. 10-PENALTIES (JUNE 1977) Any officer, director, agent, employee or such other person connected in any capacity with this contract or any subcontract thereunder that embezzles, willfully misapplies, steals or obtains by fraud any of the money, funds, assets or property provided through the contract shall be fined not more than $10,000 or imprisoned for not more than two years, or both; Provided, That if the amount embezzled, misapplied, stolen, or obtained by fraud does not exceed $100, such person shall be fined not more than $1,000 or imprisoned not more than one year, or both. (b) The Contractor agrees to insert this clause in all subcontracts. (End of clause) CLAUSE NO. 11—BUY AMERICAN ACT (JUNE 1977) (a) In acquiring end products, the Buy American Act (41 U.S. Code 10a-d) provides that the Government give preference to domestic source end products. For the purpose of this clause: (i) "Components" means those articles, materials, and supplies, which are directly incorporated in the end products; (ii) "End products" means those articles, materials, and supplies, which are to be acquired under this contract for public use; and (iii) "A domestic source end product" means (A) an unmanufactured end product which has been mined or produced in the United States and (B) an end product manufactured in the United States if the cost of the components thereof which are mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. For the purposes of this (a)(iii)(B), components of foreign origin of the same type or kind as the products referred to in (b) (ii) or (iii) of this clause shall be treated as components mined, produced, or manufactured in the United States. (b) The Contractor agrees that there will be delivered under this contract only domestic source end products, except end products: (i) Which are for use outside the United States; (ii) Which the Government determines are not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities and of a satisfactory quality; (iii) As to which the Secretary determines the domestic preference to be inconsistent with the the public interest; or (iv) As to which the Secretary determines the cost to the Government to be unreasonable. (The foregoing requirements are ad ministered in accordance with Executive Order No. 10582, dated December 17, 1954). (End of clause) CLAUSE NO. 12-EQUAL OPPORTUNITY (JUNE 1977) Subject to the Indian preference requirements of Clause 17, during the performance of this contract the Contractor agrees as follows: (a) The Contractor will not discriminate against any employee or applicant for employment because of race, creed, color, or national origin. The Contractor will take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, creed, color, or national origin. Such action shall include, but not be limited to, the following: Employment, upgrading, demotion, or transfer; recruitment or recruitment advertising; layoff or termination, rates of pay or other forms of compensation; and selection for training, including apprenticeship. The Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the Contracting Officer setting forth the provisions of this Equal Opportunity clause. (b) The Contractor will, in all solicitations or advertisement for employees placed by or on behalf of the Contractor, state that all qualified applicants will receive consideration for employment without regard to race, creed, color, or national origin. (c) The Contractor will send to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, a notice, to be provided by the agency Contracting Officer, advising the labor union or workers representative of the Contractor's commitments under this Equal Opportunity clause, and shall post copies of the notice in conspicuous places available to employees and applicants for employment. (d) The Contractor will comply with all provisions of Executive Order No. 11246 of Sepember 24, 1965, and of the rules, regulations and relevant orders of the Secretary of Labor. (e) The Contrator will furnish all information and reports required by executive Order No. 11246 of September 24, 1965, and by the rules, regulations, and orders of the Secretary of Labor, or pursuant thereto, and will permit access to its books, records, and accounts by the contracting agency and the secretary of Labor for purposes of investigation to ascertain compliance with such rules, regulations, and orders. (f) In the event of the Contractor's noncompliance with the Equal Opportunity clause of this contract or with any of the |