policies and practices, property accounting and control, wage and salary plans and rate structures, personnel policies and practices, etc.; (ii) Processing of disputes under the Disputes clause and any resultant appeals; (iii) Modification or termination of the contract; and (iv) Determination of the allowability of cost charges to incentive or costreimbursement type contracts and progress payments under fixed-price contracts. This is especially important when award is made to new organizations or those with financial weaknesses. (d) The contracting officer is responsible for assuring that contractor performance and contract monitoring are carried out in conformance with contract provisions. If performance is not satisfactory or if problems are anticipated, it is essential that the contracting officer take immediate action to protect the Government's rights under the contract. The contracting officer shall notify his/her immediate supervisor of problems that cannot be resolved within contract limitations and whenever contract or program objectives are not met. The notification shall include a statement of action being taken by the contracting officer. (e) Contract cost and manpower reporting shall be required on all cost-reimbursement type contracts financed under letter of credit or Departmental Federal Assistance Financing System (DFAFS) methods of payment regardless of dollar value, and on all other cost-reimbursement type contracts of $100,000 or more. Financial reporting may be required on cost-reimbursement contracts under $100,000, when financed by other than the letter of credit or DFAFS methods, but only if it is necessary for effective contract administration. Financial and manpower information may be submitted either as a separate contract financial report or as an addendum to a public voucher, as prescribed by the contracting officer. Frequency, format (including instructions), extent, structure (including cost elements and labor categories), and distribution of reporting fall within the discretion of the contracting officer. The contracting offi cer shall set forth financial reporting requirements in all applicable RFPs and contracts, shall limit the requirements to those necessary for effectual cost and manpower management of the contract, and shall avoid the use of reporting requirements that are unduly burdensome on the contractor. [49 FR 14024, Apr. 9, 1984, as amended at 54 FR 43966, Oct. 30, 1989; 54 FR 47750, Nov. 16, 1989] 342.7003 Withholding of contract payments. 342.7003-1 Policy. (a) All solicitations and resultant contracts shall contain a withholding of contract payments clause and an excusable delays clause or a clause which incorporates the definition of excusable delays. These clauses are contained in the Department's contract general provisions. (b) The transmittal letter used to convey the contract to each contractor shall contain a notice which highlights the contractor's agreement with the withholding of contract payments clause. (c) No contract payment shall be made when any report required to be submitted by the contractor is overdue, or the contractor fails to perform or deliver work or services as required by the contract. (d) The contracting officer shall issue a ten-day cure notice or initiate appropriate termination action for any failure in the contractor's performance as stated in the preceding paragraph (c). 342.7003-2 Procedures. (a) The contracting officer is responsible for initiating immediate action to protect the Government's rights whenever the contractor fails to comply with either the delivery or reporting provisions of the contract. Compliance with the reporting provisions includes those reports to be submitted directly to the payment office. If such a report is not submitted on time, the contracting officer is to be notified promptly by the payment office. (b) When the contract contains a termination for default clause, the contractor's failure to either submit any required report when due or perform or deliver services or work when required by the contract is to be considered a default in performance. In either circumstance, the contracting officer is to immediately issue a formal ten-day cure notice pursuant to the default clause. The cure notice is to follow the format prescribed in FAR 49.607 and is to include a statement to the effect that contract payments will be withheld if the default is not cured or is not determined to be excusable. (1) If the default is cured or is determined to be excusable, the contracting officer is not to initiate the withholding action. (2) If the default is not determined to be excusable or a response is not received within the allotted time, the contracting officer is to initiate withholding action on all contract payments and is to determine whether termination for default or other action would be in the best interest of the Government. (c) When the contract does not contain a termination for default clause, the contractor's failure to either submit any required report when due or perform or deliver services or work when required by the contract is to be considered a failure to perform. In either circumstance, the contracting officer is to immediately issue a written notice to the contractor specifying the failure and providing a period of ten days, or a longer period as determined necessary by the contracting officer, in which the contractor is to cure the failure or establish an excusable delay. The contracting officer is to include a statement in the written notice to the effect that contract payments will be withheld if the failure is not cured or is not determined to be excusable. (1) If the failure is cured or is determined to be excusable, the contracting officer is not to initiate the withholding action. (2) If the failure is not determined to be excusable or a response is not received within the allotted time, the contracting officer is to initiate withholding action on all contract pay ments and is to determine whether termination for convenience or other action would be in the best interest of the Government. (d) The contracting officer should consult FAR Subpart 49.4 for further guidance before taking any of the actions described in this section. 342.7003-3 Withholding payments. (a) When making the determination that contract payments should be withheld in accordance with the Withholding of Contract Payments clause, the contracting officer is to immediately notify the servicing finance office in writing of the determination to suspend payments. The notice of suspension is to contain all elements of information required by the payment office to properly identify the contract and the applicable accounts involved. (b) The contracting officer is to immediately notify the contractor in writing that payments have been suspended until the default or failure is cured. (c) When the contractor cures the default or failure, the contracting officer is to immediately notify, in writing, all recipients of the notice of suspension that the suspension is to be lifted and contract payments are to be resumed. (d) When exercising actions regarding the withholding of payment procedures, the contracting officer must be careful not to waive any of the Government's rights when corresponding with the contractor or when taking any other actions. Subpart 342.71—Administrative Actions for Cost Overruns 342.7100 Scope of subpart. This subpart sets forth the procedures to be followed when a cost overrun is anticipated; i.e., the allowable actual cost of performing a cost-reimbursement type contract is expected to exceed the total estimated cost specified in the contract. 342.7101 Applicability. This subpart applies to the administration of cost-reimbursement type 50-187 0-92--5 342.7103-2 Procedures. (a) Upon notification that a cost overrun is anticipated, the contracting officer shall inform the contractor to submit a request for additional funds which is to include: (1) Name and address of contractor. (2) Contract number and expiration date. (3) Contract item(s) and amount(s) creating the overrun. (4) The elements of cost which changed from the original estimate (i.e., labor, material, travel, overhead, etc.) to be furnished in the following format: (i) Original estimate, (ii) Costs incurred to date, (iii) Estimated cost to completion, (iv) Revised estimate, and (v) Amount of adjustment. (5) The factors responsible for the increase, i.e., error in estimate, changed conditions, etc. (6) The latest date by which funds must be available for commitment to avoid contract slippage, work stoppage, or other program impairment. (b) When the contractor submits a notice of an impending overrun, the contracting officer shall: (1) Immediately advise the appropriate program office and furnish a copy of the notice and any other data received; (2) Request audit or cost advisory services, and technical support, as necessary, for evaluation of information and data received; and (3) Maintain continuous follow-up with the program office in order to obtain a timely decision as to whether the work under the contract should be continued and additional funds provided, or the contract terminated. The decision of the program office must be supported by an appropriate written statement and funding authority, or a formal request for termination, when applicable. After a programming and funding decision is received from the program office, the contracting officer shall promptly notify the contractor in writing that: (i) A specified amount of additional funds has been allotted to the contract by a contractual instrument; or (ii) Work will be discontinued when the funds allotted to the contract have been exhausted, and that any work performed after that date is at the contractor's risk; or (iii) The Government is considering whether additional funds should be allotted to the contract and will notify the contractor as soon as possible, but that any work performed after the funds then allocated to the contract have been exhausted is at the contractor's risk. Timely, formal notification of the Government's intention is essential in order to preclude loss of contractual rights in the event of dispute, termination, or litigation. (c) If program requirements permit, contracting officers should refrain from issuing any contractual docu ments which will require new work or an extension of time, pending resolution of an overrun or additional fund request. 342.7104 Contract modifications. (a) Modifications to contracts containing the Limitation of Cost clause shall include either: (1) A provision increasing the estimated or ceiling amount referred to in the Limitation of Cost clause of the contract and stating that the clause will thereafter apply in respect to the increase amount; or (2) A provision stating that the estimated or ceiling amount referred to in the contract is not changed by the modification and that the Limitation of Cost clause will continue to apply with respect to the amount in effect prior to the modification. (b) A fixed-fee provided in a contract shall not be changed when funding a cost overrun. Changes in fixed-fee will be made only to reflect changes in the Scope of work which justify an increase or decrease in fee. PART 345-GOVERNMENT PROPERTY Subpart 345.3—Providing Government Property to Contractors Sec. 345.370 Providing Government property (in general). Subpart 345.4—Contractor Use and Rental of Government Property 345.405 Contracts with foreign governments or international organizations. AUTHORITY: 5 U.S.C. 301; 40 U.S.C. 486(c). SOURCE: 49 FR 14030, Apr. 9, 1984, unless otherwise noted. Subpart 345.3-Providing Government Property to Contractors 345.370 Providing Government property (in general). (a) A contractor may be provided Government property or allowed to acquire such property at Government expense upon determination that: (1) No practicable or economical alternative exists; e.g., acquisition from other sources, utilization of subcon tractors, rental of property, or modification of program project requirements, etc.; (2) The Government receives adequate consideration for providing the property; or (3) Furnishing Government property is likely to result in substantially lower cost to the Government for the items produced or services rendered when all costs involved (e.g., transportation, installation, modification, maintenance, etc.) are compared with the cost to the Government of the contractor's use of privately-owned property. (b) The determination that it is necessary to provide a contractor or subcontractor with property will be made by the contracting officer with the advice of the agency property official. (c) If the program office is aware, prior to the submission of the request for contract, that it will be necessary to provide prospective contractors with property, a written justification must accompany the request for contract to the contracting activity. Subpart 345.4—Contractor Use and Rental of Government Property 345.405 Contracts with foreign governments or international organizations. Upon the request of a foreign government or international organization, or a contractor certifying that it is acting on behalf of a foreign government or international organization, the contracting officer, with advice from the agency property official cognizant of Government property located in the United States, its possessions, or Puerto Rico, may give written approval for its use without charge on contracts or subcontracts thereunder if: (a) The foreign government or international organization would be authorized to place the contract with the activity concerned under the Foreign Assistance Act of 1961, as amended, or such use is authorized by an agreement with the foreign government; (b) The foreign government's placement of the contract directly with the contractor is consistent with the best interests of the United States; (c) It appears that the foreign government will place the contract with the contractor whether or not use is authorized, and no competitive pricing advantage will accrue to the contractor by virtue of its use; (d) The contractor agrees that no charge for the use of the property will be included in the price charged the foreign government under the contract; and (e) The use will not interfere with foreseeable requirements of the United States. |