Cases Decided in the United States Court of Claims ... with Report of Decisions of the Supreme Court in Court of Claims Cases, Volume 116The Court, 1950 |
From inside the book
Results 1-5 of 88
Page 1
... Plant on the Columbia River in the State of Washington , plaintiffs filed their petition enumerating and setting forth originally 29 * causes of action , several of which were later abandoned . Upon the evidence and the report of the ...
... Plant on the Columbia River in the State of Washington , plaintiffs filed their petition enumerating and setting forth originally 29 * causes of action , several of which were later abandoned . Upon the evidence and the report of the ...
Page 8
... Plant as covered by items 1 to 85 inclusive , of the schedule of Specifications No. 570 , Columbia Basin Project , Washington , for the con- sideration of $ 29,339,301.50 , in strict accordance with the specifications , schedules , and ...
... Plant as covered by items 1 to 85 inclusive , of the schedule of Specifications No. 570 , Columbia Basin Project , Washington , for the con- sideration of $ 29,339,301.50 , in strict accordance with the specifications , schedules , and ...
Page 10
... plant containing eighteen 105,000 kilowatt units . The river channel section of the dam will have an overflow spillway 1,800 feet long , at each side of which , and immediately below the dam abut- ments , 9 units of the power plant will ...
... plant containing eighteen 105,000 kilowatt units . The river channel section of the dam will have an overflow spillway 1,800 feet long , at each side of which , and immediately below the dam abut- ments , 9 units of the power plant will ...
Page 11
... plant , tools , equipment , overhead costs , and such consumable supplies as may be turned over to the Government as herein provided , plus ten ( 10 ) percent of such total cost 11. Sometime during the spring of 1935 the contracting ...
... plant , tools , equipment , overhead costs , and such consumable supplies as may be turned over to the Government as herein provided , plus ten ( 10 ) percent of such total cost 11. Sometime during the spring of 1935 the contracting ...
Page 12
... plant to meet such conditions . In the opinion of the contracting officer those changes are necessary and desirable . In lieu of constructing the Grand Coulee Dam and the appurtenant works in accordance with the drawings and ...
... plant to meet such conditions . In the opinion of the contracting officer those changes are necessary and desirable . In lieu of constructing the Grand Coulee Dam and the appurtenant works in accordance with the drawings and ...
Other editions - View all
Common terms and phrases
accordance acres action actual additional agreed allowed amount appeal applicable approved authorized basis Board building cause change order charge claim Company compensation completion concrete construction contained contracting officer contractor Corporation cost Court covered damages December decision defendant defendant's delay Department determined directed drawings effect engineer entered entitled equipment evidence excavation fact feet filed findings follows forms furnished further Government grout held Housing increased Indians installed interest issued January Judge judgment July June labor land letter lumber March material ment necessary November October operation Opinion paid paragraph parties patent payment performed period petition placed plaintiff plant prior purchase question railroad reasonable received record recover referred removal Reporter's Statement representative reservation result rock schedule September Shipping shown specifications Stat suit tion United vessel yard
Popular passages
Page 360 - Contractor, including, but not restricted to, acts of God, or of the public enemy, acts of the Government...
Page 397 - No person who holds an office the salary or annual compensation attached to which amounts to the sum of two thousand five hundred dollars shall be appointed to or hold any other office to which compensation is attached unless specially heretofore or hereafter specially authorized thereto by law...
Page 359 - Officer in writing of: (1) subsurface or latent physical conditions at the site differing materially from those indicated in this contract, or (2) unknown physical conditions at the site, of an unusual nature, differing materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in this contract.
Page xx - To confer jurisdiction upon the Court of Claims to hear, determine, and render judgment upon the claim of Herbert M.
Page 514 - Is permitted only upon the condition that every such laborer and mechanic shall be compensated for all hours worked In excess of eight hours per day at not less than one and one-half times the basic rate of pay.
Page 575 - The Emergency Court of Appeals, and the Supreme Court upon review of judgments and orders of the Emergency Court of Appeals, shall have exclusive jurisdiction to determine the validity of any regulation or order issued under section 2...
Page 295 - ... remission or mitigation of such fine, penalty, or forfeiture, the Secretary of the Treasury, or the Secretary of Commerce, if he finds that such fine, penalty, or forfeiture was incurred without willful negligence or without any intention on the part of the petitioner to defraud the revenue or to violate the law...
Page 221 - If the Contractor refuses or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this contract, or any extension thereof, or fails to complete said work within such time, the Government may, by written notice to the Contractor, terminate his right to proceed with the work or such part of the work as to which there has been delay.
Page 671 - No interest shall be allowed on any claim up to the time of the rendition of judgment by the Court of Claims, unless upon a contract expressly stipulating for the payment of interest...
Page 746 - In the event It Is found by the contracting officer that any laborer or mechanic employed by the contractor or any subcontractor directly on the site of the work covered by the contract has been or is being paid a rate of wages less than the rate of wages required by the contract to be paid...