The Code of Federal Regulations of the United States of AmericaU.S. Government Printing Office, 1981 The Code of Federal Regulations is the codification of the general and permanent rules published in the Federal Register by the executive departments and agencies of the Federal Government. |
From inside the book
Results 1-5 of 100
Page i
... General Services Administration as a Special Edition of the Federal Register NATIONAL ARCHIVES LITTERA SCRIPTA MANET THE * 1934 OF THE UNITED STATES OF FEDERAL REGULATIONS New Publication List of CFR Sections Affected. Jasemen.
... General Services Administration as a Special Edition of the Federal Register NATIONAL ARCHIVES LITTERA SCRIPTA MANET THE * 1934 OF THE UNITED STATES OF FEDERAL REGULATIONS New Publication List of CFR Sections Affected. Jasemen.
Page ix
... Administration . In the remaining chapters of Subtitle C are the imple- menting and supplementing property management regulations issued by individ- ual Government agencies . Those regulations which implement Chapter 101 are numerically ...
... Administration . In the remaining chapters of Subtitle C are the imple- menting and supplementing property management regulations issued by individ- ual Government agencies . Those regulations which implement Chapter 101 are numerically ...
Page 20
... Administration . 1-12.805-1 Duties of agencies . 1-12.805-2 Educational responsibility . 1-12.805-3 Notices to be posted . 1-12.805-4 Reports and other required in- formation . 1-12.805-5 Compliance reviews . 1-12.805-6 Complaints . 1 ...
... Administration . 1-12.805-1 Duties of agencies . 1-12.805-2 Educational responsibility . 1-12.805-3 Notices to be posted . 1-12.805-4 Reports and other required in- formation . 1-12.805-5 Compliance reviews . 1-12.805-6 Complaints . 1 ...
Page 28
... Administration in accordance with the procedures in § 1-1.708 . If SBA agrees with the contracting offi- cer that the concern is ineligible , SBA will forward the matter to the Secre- tary of Labor for a final determination of ...
... Administration in accordance with the procedures in § 1-1.708 . If SBA agrees with the contracting offi- cer that the concern is ineligible , SBA will forward the matter to the Secre- tary of Labor for a final determination of ...
Page 39
... Administration . § 1-12.805-1 Duties of agencies . 1 ( a ) General responsibility . Each agency shall be primarily responsible for obtaining compliance with the Equal Opportunity clause , the Order , the regulations of the Secretary of ...
... Administration . § 1-12.805-1 Duties of agencies . 1 ( a ) General responsibility . Each agency shall be primarily responsible for obtaining compliance with the Equal Opportunity clause , the Order , the regulations of the Secretary of ...
Other editions - View all
Common terms and phrases
activities Administration advance payments advertising allocated allowable amended amount applicable appropriate approval Architect-Engineer assets assignment award basis bidder bids bond certificate charges cluding compensation compliance contract price contracting officer contractor Cost Accounting Standards cost objective costs incurred Davis-Bacon Act depreciation direct employees Equal Opportunity clause equipment ernment Executive Agencies Executive Order exemption expenses extent facilities fringe benefits furnished Government grant indirect costs inspection institution July 24 lease material ment negotiated offeror organization otherwise paragraph percent performance period prescribed prime contractor prior procedures procurement progress payments proposed purchase purpose pursuant quired reasonable regulations Reinsurance request Scope of subpart Secretary of Labor shipment sions small business concerns solicitation specific sponsored agreements Standard Form subcon subcontracts submitted supplies surety term terminal emulation termination tion tract tractor unallowable United wage determination
Popular passages
Page 198 - ... (6) In the event of the contractor's noncompliance with the nondiscrimination clauses of this contract or with any of such rules, regulations, or orders, this contract may be cancelled, terminated, or suspended...
Page 218 - Contractor from the Government under this contract may be assigned to a bank, trust company, or other financing institution, including any Federal lending agency, and may thereafter be further assigned and reassigned to any such institution. Any such assignment or reassignment shall cover all amounts payable under this contract and not already paid, and shall not be made to more than one party, except that any such assignment or reassignment may be made to one party as agent or trustee for two or...
Page 240 - The Contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees or bona fide established commercial or selling agencies maintained by the Contractor for the purpose of securing business.
Page 221 - The contractor will send to each labor union or representative of workers with which he has a collective bargaining agreement or other contract or understanding, a notice, to be provided by the agency contracting officer, advising the labor union or workers' representative of the contractor's commitments under Section 202 of Executive Order No.
Page 218 - Disputes" clause does not preclude consideration of law questions in connection with decisions provided for in paragraph (a) above: Provided, That nothing in this contract shall be construed as making final the decision of any administrative official, representative or board on a question of law.
Page 236 - CHANGES The Contracting Officer may at any time, by a written order, and without notice to the sureties, make changes, within the general scope of this contract, in any one or more of the following; (i) Drawings, designs, or specifications, where the supplies to be furnished are to be specially manufactured for the Government in accordance therewith; (ii) method of shipment or packing; and (iii) place of delivery.
Page 218 - Officer grants a further period of time before the date of final payment under the contract), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of the delay and extend the time for completing the work when, in his judgment, the findings of fact justify such an extension, and his findings of fact shall be final and conclusive on the parties subject only to appeal as provided in the clause of this contract entitled "Disputes.
Page 424 - The rights and remedies of the Government provided in this clause shall not be exclusive and are In addition to any other rights and remedies provided by law or under this contract.
Page 218 - DISPUTES (a) Except as otherwise provided in this contract, any dispute concerning a question of fact arising under this contract which is not disposed of by agreement shall be decided by the Contracting Officer, who shall reduce his decision to writing and mail or otherwise furnish a copy thereof to the Contractor. The decision of the Contracting Officer shall be final and conclusive unless, within 30 days from the date of receipt of such copy, the Contractor mails or otherwise furnishes to the...
Page 34 - In the event of the contractor's noncompliance with the equal opportunity clause of this contract or with any of the said rules, regulations, or orders, this contract may be canceled, terminated or suspended, in whole or in part, and the contractor may be declared ineligible for further Government contracts in accordance with procedures authorized in Executive Order No.